Epstein Secrets

On behalf of Andrew P. Cohen Executive Director - Santa Monica California Registration Number (Printe 09 atur LS. (Title) cc: Andrew P. Cohen, Robert Jernigan, hilla Leiserowitz, Joe Harris EFTA00605628 Gensler Little St. James Pool Area and Screening Room Agreement for Architectural Services Septembe

istration. Gensler will assist Client with Construction Administration. Gensler's Construction Administration services will begin with the award of the Construction Contract and end thirty (30) days after Substantial Completion or when Gensler signs the Contractor's final payment application, whichever occurs first. 3.

(Date) (Title) On behalf of Andrew P. Cohen Executive Director - Santa Monica Office, California Registration Number C12855 cc: Andrew P. Cohen, Robert Jernigan, filla Leiserowitz, Joe Harris /OA/ (Date) EFTA00724814 Gensler Little St. James Pool Area and Screening Room Agreement for Architectural Servi

istration. Gensler will assist Client with Construction Administration. Gensler's Construction Administration services will begin with the award of the Construction Contract and end thirty (30) days after Substantial Completion or when Gensler signs the Contractor's final payment application, whichever occurs first. 3.

(Title) (Date) On behalf of Andrew P. Cohen Executive Director - Santa Monica Office, California Registration Number C12855 cc: Andrew P. Cohen, Robert Jernigan, NIla Leiserowitz, Joe Harris EFTA00727153 Gensler Little St. James Pool Area and Screening Room Agreement for Architectural Services September

istration. Gensler will assist Client with Construction Administration. Gensler's Construction Administration services will begin with the award of the Construction Contract and end thirty (30) days after Substantial Completion or when Gensler signs the Contractor's final payment application, whichever occurs first. 3.