Epstein Secrets

ion in accordance with the Contract Documents. § 3.4.6 PROJECT COMPLETION The Architect shall conduct inspections to determine the date or dates of Substantial Completion and the date of final completion; issue Certificates of Substantial Completion; receive from the Contractor and forward to the Owner, for the Owner

arbitration which, unless the parties mutually agree otherwise, shall be administered by the American Arbitration Association in accordance with its Construction Industry Arbitration Rules in effect on the date of the Agreement. Init. AIA Document B104"' - 2007. CopyrightO1974,1978, 1987, 1997 and 2007 by The American Institute of Ar

work to be corrected and review the corrective work to completion. The Architect shall review the status of construction to determine the dates of Substantial Completion and Final Completion. COMPENSATION Initial Payment An initial payment retainer of two thousand dollars j$2,000.001 shall be paid to the Architect

ndustry Mediation Rules for the American Arbitration Association currently in effect. If not resolved. then the dispute or claim shall he subject to Construction Industry Arbitration Rules of the American Arbitration Association currently in effect. The Mediation and Arbitration shall take place in St. Thomas. U.S. Virgin Islands. 12.

work to be corrected and review the corrective work to completion. The Architect shall review the status of construction to determine the dates of Substantial Completion and Final Completion. COMPENSATION Initial Payment An initial payment retainer of two thousand dollars j$2,000.001 shall be paid to the Architect

ndustry Mediation Rules for the American Arbitration Association currently in effect. If not resolved. then the dispute or claim shall he subject to Construction Industry Arbitration Rules of the American Arbitration Association currently in effect. The Mediation and Arbitration shall take place in St. Thomas. U.S. Virgin Islands. 12.